TERMS AND CONDITIONS OF PURCHASE
SK biotek Ireland Limited Terms and Conditions of Purchase
These Terms and Conditions shall be applicable to all current and subsequent purchase orders issued to you from SK biotek Ireland Limited (and/or any of its subsidiaries otherwise identified to you in relation to any relevant order) (“SKBTI”). Your further supply of any goods, materials, equipment or services to SKBTI subsequent to your receipt of the Terms and Conditions shall constitute acceptance thereof by you, and same shall apply for all current and future supplies by you to SKBTI until such time as you receive any revised terms or other notice of revocation of these terms. Additional or different terms, conditions, or instructions applicable to a particular order may be agreed to in writing and specified in the body of a purchase order, or in an exhibit thereto, and, in the event of a conflict, shall take precedence over these Terms and Conditions.
1. Definitions The following words and or expressions shall for the purposes of these Terms and Conditions have the meanings ascribed to them below:
(a) “SKBTI” means SK biotek Ireland Limited and/or any subsidiary of SK biotek Ireland Limited otherwise identified in the Purchase Order;
(b) “Purchase Order” means any order by SKBTI for the supply of goods, material, equipment or services by the Vendor the parties’ agreement in respect of which shall be constituted by:
(i) these Terms and Conditions;
(ii) the document(s) issued by SKBTI to particularize and/or confirm the order;
(iii) any scope of services or work, specification, drawing or other item referenced by or attached to any document at (ii) (including without limitation the Specification) ;
(c) “Specification” means the document issued to the Vendor by SKBTI (if any) which identifies or specifies the quantities, type, performance criteria, standards or other quantitative or qualitative requirement of the goods, materials, equipment or services to be supplied pursuant to a Purchase Order;
(d) “Vendor” shall mean the vendor of the goods, materials, equipment or servicesidentified in the Purchase Order.
2. Acceptance Notwithstanding any other statement, notice, form or other document issued to SKBTI by the Vendor pursuant to any request for supply of goods, materials or equipment by SKBTI, acceptance by Vendor of each and all of the terms and conditions comprised in any Purchase Order issued pursuant to these Terms and Conditions shall be constituted by:
(a) written acknowledgement of the Purchase Order; or
(b) the shipment or delivery of any goods, materials, equipment pursuant to the Purchaser Order, or
(c) the commencement of any services to be provided pursuant to the Purchase Order .
If any of the terms and conditions contained in a Purchase Order are not acceptable, THE VENDOR MUST ADVISE SKBTI IN WRITING upon receipt of an order and shall withhold shipment of the goods or provision of services until the matter is resolved. Any term or condition proposed by the Vendor whether before or after Vendor’s receipt of this order and whether purporting to form part of or to be communicated to SKBTI shall be null and void, and of no effect for any purpose whatsoever unless the same shall have been agreed to by SKBTI and expressed in writing and signed by the duly authorized representatives of both parties hereto.
3. Entire Agreement The Purchase Order shall constitute the entire agreement between the Vendor and SKBTI in respect of the supply of the goods, material, equipment or services identified therein and shall supersede any previous negotiations, commitments and writings in respect thereof. Any purported alteration, modification, amendment or addition to any of a Purchase Order’s terms or conditions shall be void and of no effect unless the same shall have been expressed in writing and signed by the duly authorized representatives of both parties. There may be no substitutes, or variations, or partial shipments in respect of a Purchase Order without prior written approval from an authorized representative of SKBTI.
4. Electronic Commerce: For the purposes of these Terms and Conditions the parties may issue orders, invoices, payment advices and other documentation related to any supply pursuant to these Terms and Conditions in electronic or other forms. The parties consent to the issue of all such documents in electronic form.
5. Vendor’s Obligations and Warranties Vendor shall ensure and warrants that
(a) the goods, materials, equipment or services to be supplied pursuant to any Purchase Order shall be supplied in accordance with:
(i) the terms of the Purchase Order (including without limitation any Specification included therewith) and all relevant Irish standards and codes (or where no such standards exist in accordance with relevant United Kingdom standards), and applicable industry practice;
(ii) any reasonable instructions from SKBTI (and the Vendor shall comply with all such instructions);
(iii) any goods, materials or equipment supplied shall be new, fit for their respective purposes or use and shall be free from all defects in design and workmanship; and
(b) any services shall be performed with all due skill, care, diligence and expedition, and for such duration as is specified in the Purchase Order or until the services are complete in accordance with the Purchase Order or as otherwise agreed between the Vendor and SKBTI in writing. SKBTI shall be entitled to rely on the above warranties of the Vendor (and any other warranties made in respect of a Purchase Order whether made expressly or by implication) notwithstanding that SKBTI has inspected, tested, accepted or paid for the goods, materials, equipment or services.
6. Protection and Packaging: Any goods, material or equipment to be supplied pursuant to a Purchase Order shall be carefully packed and protected or bundled according to their nature, in a manner appropriate for safe and secure transit and in accordance with any special instructions contained in the Purchase Order. The cost of packing is deemed to be included in the price agreed under the Purchase Order. All packing cases and drums are nonreturnable unless otherwise specified in the Purchase Order. Where any particular storage conditions are required for the preservation of any goods, materials or equipment after their delivery to SKBTI, the Vendor shall so inform SKBTI by notice in writing and such notice shall be issued in sufficient time prior to delivery to allow SKBTI to carry out all work necessary to accommodate special storage requirements. SKBTI shall not be liable to the Vendor, and the Vendor indemnifies SKBTI, in respect of any costs, loss or damages arising from or in connection with any breach by the Vendor of this provision.
7. Markings required for shipment of Goods/Materials The Vendor shall ensure that each container used to ship any goods/materials to be supplied pursuant to any Purchase Order must be plainly identified by:
Name of Manufacturer/Vendor
SKBTI’s Purchase Order number
SKBTI’s Product Title
SKBTI’s Item Code,
Net Weight Gross Weight, and/or Tare Weight where applicable
Parcel Number of Total Parcels Shipped
Vendor’s Control Number,
Lot or Batch Number
Where required, labels shall include appropriate hazard warning labels, Risk and Safety Phrases and a 24hr emergency contact number. A Material Safety Data Sheet (RDS) shall be sent to SKBTI End-User or Environmental Health and Safety Department. A packing slip itemizing contentsshould be placed on the outside of each shipment in a protective envelope. A copy of the Purchase Order shall be included with the Vendor’s packing slip.
8. Time for Supply The supply of goods, materials, equipment or services to be provided under any Purchase Order shall be completed within the time or times, stated in the Purchase Order. SKBTI shall not be considered to have given any waiver or indulgence with respect to the Vendor’s obligations under this clause unless the same shall have been given in writing. The Vendor shall be liable for any delays in delivery of the equipment, or any part thereof by the delivery dates stated in the Schedule of Milestones. The Vendor shall pay liquidated damages calculated at the rate of one per cent (1%) per week of the Price of the Equipment so delayed for each week or part of a week which may elapse between the date(s) of delivery specified in the Purchase Order and the actual delivery of the same, up to a maximum of five per cent (5%) of the contract value of the Purchase Order so delayed. PROVIDED ALWAYS that the Vendor shall be entitled to a reasonable extension of time(s) for delivery by reason of any act of prevention by SKBTI in respect of the Purchase Order.
9. Compliance with Law Vendor guarantees and shall ensure that the goods, materials, equipment or services to be provided hereunder shall be provided in compliance with all relevant laws in relation thereto (including all acts, legislation, statutory instruments, regulations, orders, local authority regulations and legal requirements and all other directions, judgments, decisions or orders made by any court or other body with lawful jurisdiction in respect of the goods, materials, equipment or services).
10. Variations SKBTI may at any time direct a variation (including by omission of the whole or any part of the proposed supply under a Purchase Order) to the goods, materials equipment or services to be provided pursuant to the Purchase Order. No variation shall vitiate the Purchase Order. The Vendor shall not otherwise vary any supply specified under a Purchase Order. The Vendor will not make any changes that may impact the service provided to SKBTI without first notifying SKBTI and obtaining SKBTI prior written approval. The parties shall agree a price in respect of any variation directed, or in the absence of such agreement, the price to be paid to the Vendor pursuant to the Purchase Order shall be varied so as to reflect reasonable rates and prices for the varied supply of goods, materials equipment or services. Where the Vendor considers that any instruction, request or communication from SKBTI may give rise to a variation or increase the price under a Purchase Order it must within fourteen (14) days of receipt of such instruction, request or communication, give written notice to SKBTI of such circumstance arising and the full cost implications of it. The giving of such notice shall be a condition precedent to any right of the Vendor to recover any additional cost, loss or expense thereby arising. The Vendor shall not be entitled to any payment for loss of profit or similar by reason of any variation by omission directed by SKBTI.
11. Defective goods
(a) All supplies of goods, materials or equipment pursuant to any Purchase Order are subject to inspection and rejection notwithstanding prior payment. Rejected material will be returned at Vendor’s expense for transportation both ways including all related labour and packaging costs. No goods returned as defective shall be replaced without the written permission of an authorised agent of SKBTI. Rejected goods shall be at the Vendor’s risk as soon as rejection is notified to Vendor notwithstanding same are in SKBTI’ possession.
(b) Without limiting any rights SKBTI may have at law in respect of a supply, the Vendor guarantees all supplies of goods, materials or equipment pursuant to any Purchase Order against any defects which arise due to faulty materials, workmanship or design (except materials or design furnished by SKBTI). The Vendor’s guarantee shall expire twelve (12) months from the date of completion of delivery of the whole of the supply (“the Defects Liability Period”).
(c) If during the Defects Liability Period any goods, materials or equipment are found to be defective then, without prejudice to SKBTI’s right to reject the goods, materials or equipment however slight the defect may be, they shall promptly be replaced or rectified by the Vendor at its own cost (including the cost of dismantling and reinstallation) and if removed from the site of delivery for such purpose, shall be removed from and redelivered to the site by the Vendor and re-installed at the Vendor’s cost.
(d) Upon request by SKBTI, the Vendor will investigate all complaints related within a reasonable time from request but in no event in longer than seven (7) days unless a longer timeline is agreed to in writing by . If requested by SKBTI, the Vendor will provide SKBTI with confirmation of closeout for individual complaints, and summaries of complaints received, findings and corrective actions.
12. Defective Services Without limiting any rights SKBTI may have at law in respect of a supply, where within the period of twelve (12) months from the date of completion of any services supplied pursuant to a Purchase Order, where SKBTI is of the reasonable opinion that any services the subject of a Purchase Order have been performed otherwise than in accordance with the Purchase Order, it may at its election direct the re- performance of the defective services at the Vendor’s cost, or deduct from any payments otherwise due to the Vendor the value of the defective services. Upon request by SKBTI, the Vendor will investigate all complaints related within a reasonable time from request but in no event in longer than seven (7) days unless a longer timeline is agreed to in writing by SKBTI. If requested by SKBTI, the Vendor will provide SKBTI with confirmation of closeout for individual complaints, and summaries of complaints received, findings and corrective actions.
13. SKBTI Rights in Respect of Defects If the Vendor fails to promptly make good any defect or breach of a Purchase Order for which it is responsible and which has been identified to it in writing by SKBTI, then, without prejudice to any other remedies available to it and without relieving the Vendor of any of its obligations under the Purchase Order, SKBTI may after giving four (4) days written notice of its intention to the Vendor, proceed to do the work itself or to employ another to do it. The cost thereof shall be reimbursed by the Vendor and shall be recoverable from the Vendor by SKBTI as a debt due. SKBTI shall not be obliged to accept from the Vendor any goods, materials, equipment or services supplied by the Vendor after the date of any notice to replace such defective goods, materials, equipment or services.
14. Vendor’s Staff
(a) The Vendor shall ensure that all staff engaged to carry out any work associated with the provision of the goods, materials, equipment or services to be provided hereunder shall be appropriately qualified, experienced and appropriately supervised.
(b) Where the Vendor’s staff are required to enter on to any site controlled by SKBTI pursuant to a Purchase Order, the Vendor shall ensure such staff comply with any rules or requirements established by SKBTI in respect ofsafety or otherwise for the site (including without limitation the SKBTI site security rules, details of which are available on request).
(i) The Vendor shall ensure that vendor’s personnel receive all EHS and GMP training as agreed with SKBTI and that records of thistraining are available on site for audit at all times. With the exception of genuine emergencies, vendor’s personnel without induction training will not be allowed on site. It is the responsibility of the Vendor to ensure that they present themselves for training at the scheduled times only.
(ii) The Vendor will be bound by all site rules and will be informed of these during the site induction before the commencement of the 1st contract visit. The Vendor will take due cognizance of the security procedures for the site. Depending on the work activity, method statements, risk assessments, RDS sheets, evidence of Safe Pass Training, Certification Skills or other documentation may be required to be provided by the Vendor and approved by the client, before presenting to work. For certain types of work the Vendor may also need to provide additional approved personnel to comply with site procedures – e.g. Permitting, Fire Watching.
(iii) The Vendor shall confine its materials, consumables, plant and equipment to locations relative to its work areas. The Vendor shall continuously clear away rubbish generated in connection with the Services as it accumulates, and maintain and leave work areas in a clean, safe and tidy condition. Where contaminated or hazardous waste is a side product of the maintenance/work/service activity, the Vendor will be responsible for the correct management on-site of this waste. Any contaminated or hazardous waste is to be disposed of in accordance with national law and SKBTI EHS procedures.
(c) The Vendor shall remove or exclude any of its staff from the site at SKBTI’ reasonable direction and procure replacement staff at its own cost.
(d) Vendor acknowledges and agrees that in performing services, Vendor will be acting solely as an independent contractor, and neither Vendor nor any of its employees, associated consultants, subcontractors or employees of said consultants or subcontractors shall be deemed to be employees of SKBTI for any purpose.
(e) Vendor shall:
(i) pay all of its staff promptly;
(ii) assume full liability for the payment and/or collection of all present and future national health or unemployment insurance and/or any other payroll and employment taxes imposed by law or legislation arising from the employment of the staff engaged in respect of the supply;
(iii) comply and meet any other statutory obligation or other requirement imposed by law or legislation arising by reason of the Vendor’s position as employer of its staff (except insofar as this agreement expressly provides that SKBTI is to be liable in respect of any such obligations or requirements). The Vendor shall indemnify SKBTI in respect of any claims, losses, costs, damage or other liability incurred by SKBTI by reason of a breach of this clause by the Vendor.
15. Payment and Price
(a) Subject to any term of a Purchase Order and the issue by the Vendor of appropriate invoice(s), SKBTI shall pay the Vendor the price stated in the Purchase Order in accordance with any payment terms also therein stated. If no price is so stated, the goods, materials, equipment or services shall be billed at the price last quoted (or billed) by Vendor to SKBTI for the same or similar goods, materials, equipment or services or at the prevailing market price whichever is lower and shall include all costs, charges and expenses incurred until goods, materials or equipment are in the possession of SKBTI.
(b) All Vendor invoices must show the corresponding SKBTI’ Purchase Order number, each Purchase Order line number and shall include such supporting documentation as SKBTI reasonably requires. Invoices issued in breach of this clause will be returned for correction. In case of doubt concerning quality or where rejections occur, SKBTI will defer payment. Unless specified to the contrary in any Purchase Order, all invoices should be sent to:
Attn: Accounts Payable
SK biotek Ireland Ltd.
Watery Lane, Swords,
(c)Following delivery of goods, materials, equipment or services, all payments due to the Vendor shall be made by SKBTI within ninety (90) days of the presentation by the Vendor of the appropriate invoice(s), unless agreed otherwise.
(d) SKBTI may set off against any amount payable to the Vendor pursuant to a Purchase Order, amount otherwise due to SKBTI from the Vendor.
16. Title to Goods Title to all goods, materials or equipment to be supplied pursuant to a Purchase Order whether completed and ready for delivery to SKBTI or merely intended for incorporation into other goods, materials or equipment the subject of the Purchase Order or to be supplied as part of the services to be provided pursuant to the Purchase Order, shall pass to SKBTI at the earliest to occur of the following:
(a) on payment by SKBTI of any instalment of the price stated in the Purchase Order (in respect of any goods, materials or equipment) where the goods, materials or equipment are at that time already in the Vendor’s premises, or
(b) after payment by SKBTI of any instalment of such price, as soon as the goods, materials or equipment arrive in the Vendor’s premises; or
(c) when SKBTI receives possession of same whether or not payment thereof has been made or is due. When under the foregoing provisions of this clause property passes to SKBTI and where goods remain in possession or control of the Vendor they shall be held by the Vendor on trust for SKBTI. The Vendor shall, where practicable, affix thereto a label or other legible marks stating that such goods, materials or equipment, as the case may be, are the property of SKBTI and/or its agents shall be entitled at all reasonable times to carry out inspections at the Vendor’s and its sub-contractors’ premises to ensure that the provisions of this clause have been observed and if not observed to affix a label or mark as aforesaid and the cost thereof shall be reimbursed by the Vendor.
17. Risk Vendor shall remain responsible for all goods, materials or equipment ordered until SKBTI receives possession ofsame (regardless that title may have passed at an earlier time). The Vendor shall, at its own cost, insure all goods, materials and equipment to be supplied pursuant to a Purchase Order for their full replacement value while they are at its risk and shall provide SKBTI with a copy of the relevant insurance policy on request
(a) Vendor hereby agrees to indemnify and hold harmless SKBTI from all losses, liability, damage, expenses and/or claims whether in respect of any death, personal injury or property or other damage which may be sustained by or claimed against SKBTI:
(i) arising out of the use of defective materials, goods or equipment, or, as a result of negligently provided services supplied under a Purchase Order or otherwise arising out of or in connection with any breach by the Vendor of its obligations under the Purchase Order; or
(ii) arising from injury to Vendor employees while in the course of fulfilling any Purchase Order for SKBTI; or
(iii) arising from the Vendor’s use of automobiles, trucks, heavy equipment, or other vehicles in the course of fulfilling any Purchase Order;
(iv) arising out of any claim or cause of action in respect of injury or sickness or disease or death of any person or loss of or damage to any tangible property (whether real or personal) of SKBTI or of any third party to whom SKBTI may be liable, arising out of or in connection with the performance by the Vendor (including its employees agents and sub-contractors) of its obligations under any Purchase Order, or by reason of any act, omission, negligence or breach of statutory duty by the Vendor (including its employees, agents or subcontractors), and shall at its own cost defend SKBTI (following notice by SKBTI that it requires the Vendor so to do and confirmation that it will make available all the relevant information to allow the Vendor to defend) in any proceedings involving the same;
(v) arising out of any claim or cause of action for alleged patent, design or copyright infringement asserted against SKBTI out of the performance of a Purchase Order by the Vendor (or by its employees, agents or sub-contractors) including the use of tools, implements or methods employed by the Vendor;
(vi) any other act or omission of the Vendor pursuant to a Purchase Order, And the Vendor shall, at the request of SKBTI, take over the defence of any claim covered by this indemnity. The limitation period under these Terms and Conditions shall be twelve (12) years.
(a) Vendor shall effect such insurances which are legally required and/or prudently required by the Vendor’s undertaking of the provision of equipment and services to SKBTI including but not limited to:
(i) Products Liability insurance for an amount of not less than €5,000,000 per occurrence and in the annual aggregate, for the reasonable life of the equipment and in any event, for a period of not less than three years from the date of Acceptance of the equipment;
(ii) where a Purchase Order requires provision of services, the Vendor shall effect Employer’s Liability insurance with a limit of indemnity for any one claim or series of claims arising out of the one event of not less than €12,700,000 or Employer’s Liability insurance and/or Workers Compensation insurance amount as required by the laws of the country having jurisdiction over the Vendor’s employees. Such insurance cover shall include all employees of all Sub-Contractors of the Vendor engaged in the performance of the Vendor’s obligations under this Purchase Order and shall contain an indemnity to principals Clause;
(iii) Public Liability insurance with a combined bodily injury and property damage limit of not less than €5,000,000 million. Such insurance shall contain an indemnity to principals Clause and shall not include any warranties without the prior written approval of the Vendor and SKBTI;
(iv) Professional Indemnity insurance with a limit of indemnity for any one claim or series of claims arising out of the one event of not less than €2,500,000, where a Purchase Order requires provision of design, engineering, architect or construction services or other amounts as the parties may agree in writing;
(v) Motor insurance with a Third Party Property Damage limit of not less than €5,000,000.00; All insurances required must include Republic of Ireland within their respective Territorial and Jurisdictional limits.
(b) Such other policies which are legally required and/or prudently required by the Vendor’s undertaking the type of equipment design and manufacture and the provision of the services associated with these Terms and Conditions.
(c) The Vendor may be required to furnish SKBTI with certificates of insurance. Certificates shall be furnished within fourteen (14) working days of such request. Failure to provide such certificates may be taken by SKBTI to indicate that the Vendor has failed to meet its obligations to provide the insurance cover required under a Purchase Order. The Vendor shall also furnish SKBTI within fourteen (14) working days of such request with updated certificates on the renewal anniversary of any policies required hereunder.
(d) The Vendor shall give immediate written notice to SKBTI and all insured parties of which notice has been given by the Vendor in the event of cancellation or material change of the Vendor’sinsurance cover which may affect SKBTI’ or any insured party’s interest.
(e) Failure by the Vendor to provide the certificates in accordance with Sub-Clause 19(c) and/or in the event that a policy is cancelled or has a material change as referenced in Sub-Clause 19(d), may be taken by SKBTI to indicate that the Vendor has failed to meet its obligations to provide the insurance cover required under these Terms and Conditions. This shall entitle SKBTI at its sole discretion to effect and maintain such insurance or such additional insurances as SKBTI shall consider necessary to deduct the cost of any premium applicable thereto from any monies due or which may become due to the Vendor or recover the same as a debt due from the Vendor provided that the insurance cover arranged by the Vendor and in force shall have been inadequate in respect of its obligations under a Purchase Order. [printed version]
20. Patents, etc Vendor shall ensure that
(a) any goods, equipment and materials sold hereunder and every element thereof, the method of manufacture
thereof, and their use in the customary manner or in a manner suggested or recommended by Vendor or in a manner
intended by SKBTI which is known to Vendor do not; and
(b) in the provision of any services to be provided under a Purchase Order the Vendor will not infringe any
Irish or other patent, trademark or copyright and the Vendor agrees to indemnify and save harmless SKBTI and its
employees against any damages, liability, cost or expenses resulting from any claim or proceeding alleging such
infringement, provided SKBTI gives Vendor notice thereof and permits Vendor, if it so elects, to enter and defend,
settle or otherwise terminate such claim or proceeding.
21. Intellectual Property: SKBTI acknowledgesthat except to the extent SKBTI has provided any ofits own design for a supply, any goods, materials, equipment or services provided by Vendor pursuant to a Purchase Order are proprietary to the Vendor. All rightsto such goods, materials, equipment orservices not granted to SKBTI hereunder are expressly reserved to the Vendor. Without limiting the foregoing, the Vendor shall retain and reserve all intellectual property rights, title, and interest in the following:
(a) all ideas, concepts, know-how, methodologies or techniques which Vendor owned previously or independently of the supply of goods, materials, equipment or services herein, or which were conceived by Vendor during the supply of goods, materials, equipment or services herein; and
(b) any materials developed by or on behalf of Vendor previously or independently of the supply of goods, materials, equipment or services herein.
Notwithstanding the foregoing, any and all reports, plans, information, data, drawings, computer software, renditions, mock-ups, prototypes or other works created by Vendor for SKBTI in connection with the goods, materials, equipment or services provided hereunder shall be owned by SKBTI and the Vendor grants SKBTI an irrevocable royalty free license to use such material for any purpose connected with the relevant Purchase Order or any SKBTI project associated therewith.
22. ConfidentialInformation (a) Vendor agrees to hold in confidence all methods, processes, techniques, shop practices, formulae, compounds, compositions, organisms, equipment, research data, marketing and sales, information, customer lists, plans and all other know-how and trade secrets owned by SKBTI or in SKBTI’ possession and disclosed to Vendor as a result of or for the purposes of any Purchase Order. Unless required by law or until such information has been published or disclosed to the general public, Vendor agrees not to use such information for itself or others or to disclose such information to others except for the purposes of the Purchase Order and then only with SKBTI’ prior written consent.
(b) Vendor shall procure that its employees, agents and sub-contractors and their employees comply with the confidentiality obligations contained in this clause. If required by SKBTI, the Vendor shall ensure that each such employee, agent, sub-contractor and/or its employees shall prior to the commencement of any supply under a Purchase Order or at any time before its completion, sign a confidentiality agreement in a form provided by the Purchaser.
(c) Where the Vendor is required by law to disclose any confidential information, the Vendor shall notify SKBTI of the legal requirement no later than thirty (30) days prior to the date by which the disclosure must be made (or as soon as the Vendor becomes aware of the requirement where the date for disclosure is less than thirty (30) days from receipt of notice of the requirement). In these circumstances the Vendor shall provide all reasonable assistance to SKBTI in any proceedings or action SKBTI sees fit to take to remove or stay the legal requirement to disclose.
23. Non-disclosure: Neither party shall disclose any information pertaining to any transaction between the parties pursuant to these Terms and Conditions and/or any Purchase Order nor may either party advertise or promote using the name or description of the other party (including, but not limited to, disclosing the existence of these Terms and Conditions or the existence of any Purchase Order) without the express written consent of the other party except as follows:
(a) to the extent provided in Clause 22
(b) as required by law; and
(c) the Vendor may include “SKBTI” as a customer in general listings of its clients, except in press releases or other materials distributed to the media (but no SKBTI logo may be used in any listings under any circumstance).
24. Termination for fault Where:
(a) the Vendor fails to rectify a breach of any Purchase Order notified to it in writing by SKBTI within fourteen (14) days of such notice; or
(b) the Vendor commits an act of bankruptcy or being a company enters into liquidation whether compulsory or voluntary or if a receiver is appointed or if a petition to appoint an examiner is presented to the High Court in Ireland then the Purchase Order may be terminated forthwith by SKBTI in which case SKBTI shall pay to the Vendor any amounts due under the Purchase Order as at the date of termination (within ninety (90) days of receipt of an appropriate invoice) but may deduct from such amounts any additional costs or loss it has incurred or is occurred to complete any outstanding supply of goods, materials or services under the Purchase Order by reason of the termination whether by itself or others.
25. Interest In no event shall amounts due by SKBTI under any Purchase Order bear interest except as provided otherwise by law.
26. Implied Terms Nothing in these Terms and Conditions or any other term of a Purchase Order shall be construed as excluding any condition, warranty or term as to quality suitability or fitness of goods, materials, equipment or services supplied or rendered pursuant to the Purchase Order, implied into the terms of the Purchase Order under or by virtue of the Sales of Goods Act 1893-1980 or any other relevant statutory provision or at common law or otherwise howsoever.
27. Jurisdiction The validity and interpretation of the terms and conditions of any Purchase Order shall be determined by the laws of the Ireland.
28. Waiver The failure of SKBTI to enforce any of these terms and conditions shall not be construed as a waiver of its rights hereunder of any of them. No waiver by SKBTI of any breach of any of the terms or conditions of a Purchase Order shall be construed as a waiver of any subsequent breach whether of the same or of any other term or condition hereof. No waiver shall be validly made unless made in writing.
29. Assignment and Sub-Contracting Vendorshall not assign any Purchase Order orsub-contract the performance of a Purchase Order or any part thereof without the written permission of SKBTI. Breach of this condition shall entitle SKBTI to cancel the Purchase Order or at its election any part thereof. Sub-contracting shall not relieve the Vendor of its responsibility for the whole of any supply under a Purchase Order and for the timely execution thereof and the Vendor shall be responsible for the acts, defaults and neglects of its subcontractors as fully as if they were the acts, defaults and neglects of the Vendor.
(a). Both parties have a statutory right under the Construction Contracts Act 2013 (Signed of 13th of April 2016) to refer a dispute relating to payment (“Payment Dispute”) to adjudication at any time. Other disputes must be resolved in accordance with Clauses 30(c) below. The parties may agree to try to resolve Payment Disputes in accordance with Clauses 30(c)(i) and 30(c)(ii) below instead of by reference to adjudication without affecting their statutory right to refer Payment Disputes to adjudication at any time.
(b). Adjudication of Payment Disputes
(i). Either party may commence the adjudication of a Payment Dispute by serving on the other party at any time a notice of intention to refer the payment dispute to adjudication (a “Notice of Adjudication”). The Notice of Adjudication may be in the form of Annex 1 of the Code of Practice Governing the Conduct of Adjudications under the Construction Contracts Act 2013 as published by the Department of Jobs, Enterprise and Innovation (“Code of Practice”).
(ii). If either party serves a Notice of Adjudication, the parties should then attempt to appoint an adjudicator of their choice who is competent to adjudicate the payment dispute in accordance with the Code of Practice.
(iii). If the parties fail to appoint an adjudicator of their choice within five (5) days of the serving of the Notice of Adjudication, the referring party may submit a written request to the chair of the panel appointed by the Minister to appoint an adjudicator. This request shall be copied to the other party. The request shall include:
(iv). A copy of the Notice of Adjudication;
(v). A statement of when the Notice of Adjudication was served on the Responding Party and how this was done;
(vi). Any information which it is considered will assist the chair in appointing an adjudicator with the appropriate expertise to deal with a payment dispute;
(vii). The adjudication shall be conducted in accordance with the Code of Practice. Within seven (7) days of the adjudicator’s appointment the Referring Party shall refer the Payment Dispute to the adjudicator. The referral may be in the form of Annex 2 of the Code of Practice. At the same time the referring party shall send a copy of the referral and all accompanying documents to the other party. The date on which the referral is made is the start of the adjudication. The adjudicator shall reach his decision within twenty eight (28) days which he may extend to fourteen (14) days with the consent of the referring party or within such longer period as may be agreed by the parties;
(viii). In the event that a Payment Dispute is referred to adjudication and the adjudicator’s decision does not finally resolve the Payment Dispute either party is entitled to litigate the matter. The adjudicator’s decision shall be binding until overturned by Court order.
(c). Other than a Payment Dispute, or a Payment Dispute where SKBTI and the Supplier have decided will not be referred to adjudication under Clause 30 (a) and Clause 30 (b), disputes between the parties will be referred to the courts for resolution:
(i). Before initiating litigation, the parties will attempt to resolve disputes under this Agreement by negotiation. At any such conference, each party will be represented by a person having authority to agree to a resolution of the Dispute. If the dispute has not been resolved within seven (7) days of the service of the notice of dispute, or such other time as may be mutually agreed by the parties prior to the expiry of seven (7) days of the service of the notice of the dispute, then the Dispute shall be referred to the courts for resolution.
(ii). Notwithstanding the dispute, the parties will continue to comply with their obligations under this Agreement. This clause does not prevent a party from seeking urgent injunctive relief from a court.
Any notices must be in writing and will be deemed received when delivered personally, when delivered by electronic means with proof of delivery or seven (7) business days from the date mailed, if sent by registered or certified mail. Notices to SKBTI will be addressed and sent to the SKBTI Procurement Manager unless otherwise advised in writing.